Terms & Conditions

1. Acceptance of Terms

By accessing or using our website and services, you acknowledge that you have read, understood, and agree to comply with these Terms and Conditions. If you do not agree with any part of these terms, you must discontinue the use of our services and website immediately.

2. Services Provided

Newish Technology offers a variety of digital solutions. The specific scope, deliverables, timelines, and pricing for any project will be outlined in a separate Statement of Work (SOW), formal proposal, or project agreement.

• • We reserve the right to modify, suspend, or discontinue any part of our services at our sole discretion, with prior notice to active clients.
• • Any changes to the agreed-upon project scope requested by the client may result in additional charges and timeline adjustments.

3. Client Responsibilities

To ensure the timely and successful delivery of projects, clients are expected to:

• • Provide all necessary materials, content, brand assets, and API credentials in a timely manner.
• • Ensure that any materials provided do not infringe on the intellectual property rights of third parties.
• • Provide timely feedback and approvals during the design and development phases. Delays in client feedback may impact the final delivery date.

4. Payment Terms

Payment schedules and milestones will be detailed in your specific project agreement.

• • A non-refundable advance payment is typically required before any work commences.
• • Invoices are to be paid within the stipulated time frame mentioned on the invoice. We reserve the right to pause work if payments are delayed.
• • All final deliverables, source code, and live deployments will only be handed over upon receipt of full and final payment.

5. Intellectual Property Rights

Ownership of the digital products we create is handled as follows:

• • Upon full payment, the intellectual property rights of the custom code, designs, and final product transfer to the client.
• • Newish Technology retains the rights to pre-existing libraries, base code, or open-source integrations used to build the solution.
• • We reserve the right to showcase the completed project in our portfolio and marketing materials unless a strict Non-Disclosure Agreement (NDA) is signed.

6. Limitation of Liability

Newish Technology shall not be held liable for any indirect, incidental, special, or consequential damages, including but not limited to loss of profits, data, or business opportunities arising out of the use or inability to use our services. Our maximum liability for any claim arising from a project shall not exceed the total amount paid by the client for that specific project.

7. Termination of Services

Either party may terminate a project by providing written notice. In the event of termination by the client, Newish Technology shall be compensated for all work completed up to the date of termination. Any advance payments made for uncompleted phases will be evaluated and refunded based on the effort already invested.

8. Governing Law

These Terms and Conditions shall be governed by and construed in accordance with the laws of India. Any disputes arising out of or related to these terms or our services shall be subject to the exclusive jurisdiction of the courts located in Lucknow, Uttar Pradesh.